DAY-1 PROGRAMME

1. GENERAL PROVISIONS
1.1 Definitions
1.2 Interpretation
1.3 Communications
1.4 Law and Language
1.5 Priority of Documents
1.6 Contract Agreement
1.7 Assignment
1.8 Care and Supply of Documents
1.9 Confidentiality
1.10 Employer’s Use of Contractor’s Documents
1.11 Contractor’s Use of Employer’s Documents
1.12 Confidential Details
1.13 Compliance with Laws
1.14 Joint and Several Liability

2. THE EMPLOYER
2.1 Right of Access to the Site
2.2 Permits, Licences or Approvals
2.3 Employer’s Personnel
2.4 Employer’s Financial Arrangements
2.5 Employer’s Claims

3. THE EMPLOYER’S ADMINISTRATION
3.1 The Employer’s Representative
3.2 Other Employer’s Personnel
3.3 Delegated Persons
3.4 Instructions
3.5 Determinations

4. THE CONTRACTOR
4.1 Contractor’s General Obligations
4.2 Performance Security
4.3 Contractor’s Representative
4.4 Subcontractors
4.5 Nominated Subcontractors
4.6 Co-operation
4.7 Setting Out
4.8 Safety Procedures
4.9 Quality Assurance
4.10 Site Data
4.11 Sufficiency of the Contract Price
4.12 Unforeseeable Difficulties
4.13 Rights of Way and Facilities
4.14 Avoidance of Interference
4.15 Access Route
4.16 Transport of Goods
4.17 Contractor’s Equipment
4.18 Protection of the Environment
4.19 Electricity, Water and Gas
4.20 Employer’s Equipment and Free-Issue Material
4.21 Progress Reports
4.22 Security of the Site
4.23 Contractor’s Operations on Site
4.24 Fossils

5. DESIGN
5.1 General Design Obligations
5.2 Contractor’s Documents
5.3 Contractor’s Undertaking
5.4 Technical Standards and Regulations
5.5 Training
5.6 As-Built Documents
5.7 Operation and Maintenance Manuals
5.8 Design Error

6. STAFF AND LABOUR
6.1 Engagement of Staff and Labour
6.2 Rates of Wages and Conditions of Labour
6.3 Persons in the Service of Others
6.4 Labour Laws
6.5 Working Hours
6.6 Facilities for Staff and Labour
6.7 Health and Safety
6.8 Contractor’s Superintendence
6.9 Contractor’s Personnel
6.10 Records of Contractor’s Personnel and Equipment
6.11 Disorderly Conduct

7. PLANT, MATERIALS AND WORKMANSHIP
7.1 Manner of Execution
7.2 Samples
7.3 Inspection
7.4 Testing
7.5 Rejection
7.6 Remedial Work
7.7 Ownership of Plant and Materials
7.8 Royalties

8. COMMENCEMENT, DELAYS AND SUSPENSION
8.1 Commencement of Works
8.2 Time for Completion
8.3 Programme
8.4 Extension of Time for Completion
8.5 Delays Caused by Authorities
8.6 Rate of Progress
8.7 Delay Damages
8.8 Suspension of Work
8.9 Consequences of Suspension
8.10 Payment for Plant and Materials in Event of Suspension
8.11 Prolonged Suspension
8.12 Resumption of Work

DAY-2 PROGRAMME

9. TESTS ON COMPLETION
9.1 Contractor’s Obligations
9.2 Delayed Tests
9.3 Retesting
9.4 Failure to Pass Tests on Completion

10. EMPLOYER’S TAKING OVER
10.1 Taking Over of the Works and Sections
10.2 Taking Over of Parts of the Works
10.3 Interference with Tests on Completion

11. DEFECTS LIABILITY
11.1 Completion of Outstanding Work and Remedying Defects
11.2 Cost of Remedying Defects
11.3 Extension of Defects Notification Period
11.4 Failure to Remedy Defects
11.5 Removal of Defective Work
11.6 Further Tests
11.7 Right of Access
11.8 Contractor to Search
11.9 Performance Certificate
11.10 Unfulfilled Obligations
11.11 Clearance of Site

12. TESTS AFTER COMPLETION
12.1 Procedure for Tests after Completion
12.2 Delayed Tests
12.3 Retesting
12.4 Failure to Pass Tests after Completion

13. VARIATIONS AND ADJUSTMENTS
13.1 Right to Vary
13.2 Value Engineering
13.3 Variation Procedure
13.4 Payment in Applicable Currencies
13.5 Provisional Sums
13.6 Daywork
13.7 Adjustments for Changes in Legislation
13.8 Adjustments for Changes in Costs

14. CONTRACT PRICE AND PAYMENT
14.1 The Contract Price
14.2 Advance Payment
14.3 Application for Interim Payments
14.4 Schedule of Payments
14.5 Plant and Materials intended for the Works
14.6 Interim Payments
14.7 Timing of Payments
14.8 Delayed Payment
14.9 Payment of Retention Money
14.10 Statement at Completion
14.11 Application for Final Payment
14.12 Discharge
14.13 Final Payment
14.14 Cessation of Employer’s Liability
14.15 Currencies of Payment

15. TERMINATION BY EMPLOYER
15.1 Notice to Correct
15.2 Termination by Employer
15.3 Valuation at Date of Termination
15.4 Payment after Termination
15.5 Employer’s Entitlement to Termination

16. SUSPENSION AND TERMINATION BY CONTRACTOR
16.1 Contractor’s Entitlement to Suspend Work
16.2 Termination by Contractor
16.3 Cessation ofWork and Removal of Contractor’s Equipment
16.4 Payment on Termination

17. RISK AND RESPONSIBILITY
17.1 Indemnities
17.2 Contractor’s Care of the Works
17.3 Employer’s Risks
17.4 Consequences of Employer’s Risks
17.5 Intellectual and Industrial Property Rights
17.6 Limitation of Liability

18. INSURANCE
18.1 General Requirements for Insurance
18.2 Insurance for Works and Contractor’s Equipment
18.3 Insurance against Injury to Persons and Damage to Property
18.4 Insurance for Contractor’s Personnel

19. FORCE MAJEURE
19.1 Definition of Force Majeure
19.2 Notice of Force Majeure
19.3 Duty to Minimise Delay
19.4 Consequences of Force Majeure
19.5 Force Majeure Affecting Subcontractor
19.6 Optional Termination, Payment and Release
19.7 Release from Performance under the Law

20. CLAIMS, DISPUTES AND ARBITRATION
20.1 Contractor’s Claims
20.2 Appointment of the Dispute Adjudication Board
20.3 Failure to Agree Dispute Adjudication Board
20.4 Obtaining Dispute Adjudication Board’s Decision
20.5 Amicable Settlement
20.6 Arbitration
20.7 Failure to Comply with Dispute Adjudication Board’s Decision
20.8 Expiry of Dispute Adjudication Board’s Appointment