Construction Contract MDB Harmonised Ed (Version 1: May 2005 Harmonised Red Book)

Conditions of Contract for Construction (Multilateral Development Bank Harmonised Harmonised Ed. Version 1: May 2005). For Building and Engineering Works designed by the Employer. General Conditions; Particular Conditions; Forms of Tender, etc. Electronic version in encrypted PDF.

Free download:

_golden_principles_1.pdf

Group Extras

More information

Construction Contract: Conditions of Contract for Construction
FOR BUILDING AND ENGINEERING WORKS DESIGNED BY THE EMPLOYER MDB Harmonised Edition, March 2006 Version Amended Version published June 2010, see June 2010 Version Amended Version published March 2006 (First Version published May 2005) FOR USE UNDER LICENCE ON PROJECTS FUNDED BY PARTICIPATING MULTILATERAL DEVELOPMENT BANKS (MDB) FOR PROJECTS THAT ARE NOT PARTICIPATING MDB FINANCED, THE CONSTRUCTION CONTRACT, 1ST EDITION 1999, MUST BE USED.

General Conditions Particular Conditions Forms of Tender, Contract Agreement Dispute Adjudication Agreement ACKNOWLEDGEMENTS TO THE FIRST EDITION 1999 INTRODUCTION PARTICIPATING BANKS COPYRIGHT CONTENTS Conditions of Contract for Construction, which are recommended for building and engineering works designed by the Employer or by his representative, the Engineer. Under the usual arrangements for this type of contract, the Contractor constructs the works in accordance with a design provided by the Employer. However, the works may include some elements of Contractor-designed civil, mechanical, electrical and/or construction works.
		ISBN 2-88432-044-X Bound volume (100 p.) Code: FC-RA-H-AA-10
Printed : Out of Stock Electronic: General Conditions only, March 2006 Version: Unprotected PDF. Free of charge. PDF Complete Contract, March 2006 Version: General Conditions, Forms, Index, etc. Add to Order For Amended Version published June 2010, see June 2010 Version

ACKNOWLEDGEMENTS TO THE FIRST EDITION, 1999
Fédération Internationale des Ingénieurs-Conseils (FIDIC) extends special thanks to the following members of its Update Task Group: Christopher Wade (Group Leader), SWECO-VBB, Sweden; Peter L Booen (Principal Drafter), GIBB Ltd, UK; Hermann Bayerlein, Fichtner, Germany; Christopher R Seppala (Legal Adviser), White & Case, France; and José F Speziale, IATASA, Argentina. The preparation was carried out under the general direction of the FIDIC Contracts Committee comprising John B Bowcock, Consulting Engineer, UK (Chairman); Michael Mortimer-Hawkins, SwedPower, Sweden; Axel-Volkmar Jaeger, Schmidt Reuter Partner, Germany; and Hiroyuki Endo, Pacific Consultants, Japan. Various drafts were reviewed by the following persons or organisations: Mushtaq Ahmad, NESPAK, Pakistan; Peter Batty, Post Buckley International, USA; Manfred Breege, Lahmeyer International, Germany; Pablo Bueno, TYPSA, Spain; Nael G Bunni, Consulting Engineer, Ireland; Ian Fraser, Beca Carter Hollings & Ferner, New Zealand; Roy Goode, Oxford University, UK; Dan W Graham, Bristows Cooke & Carpmael, UK; Mark Griffiths, Griffiths & Armour, UK; Geoffrey F Hawker, Consulting Engineer, UK; Hesse & Steinberger, VDMA, Germany; Poul E Hvilsted, Elsamprojekt, Denmark; Gordon L Jaynes, Whitman Breed Abbott & Morgan, UK; Tonny Jensen (Chairman of FIDIC Quality Management Committee), COWI, Denmark; Philip Loots & Associates, South Africa; Neil McCole, Merz and McLellan, UK; K B (Tony) Norris, Consulting Engineer, UK; Eric Petersen, CEGELEC, France; Matthew Needham-Laing, Victoria Russell & Paul J Taylor, Berrymans Lace Mawer, UK; David R Wightman & Gerlando Butera, Nabarro Nathanson, UK; the Association of Japanese Consulting Engineers; European International Contractors; Organisme de Liaison Industries Métalliques Européennes ("ORGALIME"); the International Association of Dredging Contractors; the International Bar Association; the Asian Development Bank; and the World Bank. FIDIC wishes to record its appreciation of the time and effort devoted by all the above. The ultimate decision on the form and content of the document rests with FIDIC.

INTRODUCTION
The Multilateral Development Banks (MDBs) have for a number of years adopted the FIDIC Conditions of Contract for Construction as part of the Standard Bidding Documents which the MDBs require their borrowers or aid recipients to follow. In using the FIDIC Conditions it has been the regular practice of the MDBs to introduce additional Clauses in the Conditions of Particular Application (or “Particular Conditions”) in order to amend provisions contained in the FIDIC General Conditions. These additional clauses in many cases have standard wording which has to be repeated whenever procurement documents are being prepared for a new project. Furthermore, the provisions in bid documents, including the additional clauses contained in the Particular Conditions, varied between the MDBs, and this created inefficiencies and uncertainties amongst the users of the documents, and increased the possibilities for disputes. The problem was recognised by the Heads of Procurement (HOPs) of the MDBs as significant, as were the benefits of standardisation. In response, the HOPs resolved to harmonise their bid documents on an international basis, by making use of the FIDIC General Conditions. For this purpose, the HOPs further resolved that there should be a modified form of the FIDIC Conditions of Contract for Construction, 1st Edition 1999, in which the General Conditions would contain the standard wording which previously has been incorporated by MDBs in the Particular Conditions. FIDIC also recognised the major benefits to the users of the contracts of harmonisation and the inclusion in the General Conditions of the main common changes required by Particular Conditions in MDB contracts. Accordingly, the Federation was pleased to work with the HOPs to produce this MDB Harmonised Edition of the 1999 conditions for MDB contracts. It is believed that the modified, or harmonised document, will simplify use of the FIDIC Conditions of Contract not only for the MDBs and their borrowers, but also for others involved with project procurement, such as consulting engineers, contractors and contract lawyers. Use of the harmonised conditions should significantly reduce the number of additions and amendments to be included in the Particular Conditions. Nevertheless, most projects will have special requirements which will necessitate some specific changes. This harmonised document therefore contains provision for Particular Conditions, as has become the practice in other FIDIC documents. This MDB Harmonised Edition also includes sample forms for Contract Data, Securities, Bonds, Guarantees and Dispute Board agreements. In general, this harmonised document follows earlier FIDIC risk sharing principles for the type of contract for which they were prepared. In most cases, the amendments which have been made to produce the MDB Harmonised Edition of the FIDIC General Conditions for Construction are those arising from the requirements of the MDBs, except for some minor changes of an editorial nature. However, in the case of the dispute provisions contained in Clauses 20.2 to 20.8 and in the associated Appendix, the opportunity has been taken to make other amendments which FIDIC considers an improvement on earlier wording in the of the Construction Contract, 1st Edition 1999. A draft of this MDB Harmonised Edition was circulated for comment to interested parties, prior to its finalization. All of the comments received were considered by FIDIC and some have been incorporated. Other comments will be reviewed again when in due course FIDIC produces a second edition of its Construction Contract. The insurance provisions given in Clause 18 of the document remain unchanged from the 1st Edition 1999, although some commentators have suggested an alternative approach to dealing with this specialised topic. In particular, Employers may wish to consider arranging for a dedicated single policy for the project which would cover all necessary insurances. The advantage of such an approach is that it would avoid gaps or other misunderstandings in the insurances provided, including possible duplication of cover. If an Employer decides to arrange a single insurance policy, then a copy of that policy should be made available to tenderers during the tender period. FIDIC recommends that Employers should obtain, at an early stage of project procurement, expert advice on insurance matters. The MDBs listed in the section "Participating Banks" have participated in the preparation of the MDB Harmonised Edition. It is understood that all of them will adopt this edition of the FIDIC document in their Standard Bidding Documents.

PARTICIPATING BANKS
The Participating Banks listed below have participated in the preparation of the Multilateral Development Bank (MDB) Harmonised Edition of the FIDIC Conditions of Contract for Construction. It is understood that all of them will adopt this edition of the FIDIC document in their Standard Bidding Documents. The MDB Harmonised Edition is for use on projects financed in whole or in part by a Participating Bank. African Development Bank Asian Development Bank Black Sea Trade and Development Bank Council of Europe Development Bank Caribbean Development Bank European Bank for Reconstruction and Development Inter-American Development Bank International Bank for Reconstruction and Development (The World Bank)
COPYRIGHT
Copyright Under the terms of the licence agreement with a Participating Bank, the sole Copyright owner of the Conditions of Contract for Construction which includes the MDB Harmonised General Conditions of Contract is FIDIC. Each Participating Bank shall ensure that a) the credit "MDB Harmonised Conditions of Contract for Construction - for participating development bank-financed contract use only. © FIDIC 2005 - No reproduction of this document is permitted." appears on each page of each copy of the MDB Harmonised General Conditions of Contract included in SBDs, printed or in electronic format; and b) the following FIDIC Copyright notice appears on the first page of each MDB Harmonised General Conditions of Contract prepared by users: “© FIDIC 2005. All rights reserved. The Copyright owner of this work is the International Federation of Consulting Engineers - FIDIC. This publication is exclusive for use as provided under the License Agreement dated [Date] between [Name of MDB] and FIDIC, and, consequently, no part of this publication may be reproduced, translated, adapted, stored in a retrieval system or communicated, in any form or by any means, whether mechanical, electronic, magnetic, photocopying, recording or otherwise, without prior permission in writing from FIDIC. To request such permission, please contact: FIDIC, Case Postale 311, CH-1215 Geneva 15, Switzerland; Tel. +41 22 799 49 00; Fax +41 22 799 49 01; E-mail: [email protected]. FIDIC is not responsible for the accuracy or completeness of translations of this publication unless such translation explicitly indicates otherwise.”

CONTENTS
A. GENERAL CONDITIONS DEFINITIONS LISTED ALPHABETICALLY 1. GENERAL PROVISIONS 1.1 Definitions 1.2 Interpretation 1.3 Communications 1.4 Law and Language 1.5 Priority of Documents 1.6 Contract Agreement 1.7 Assignment 1.8 Care and Supply of Documents 1.9 Delayed Drawings or Instructions 1.10 Employer's Use of Contractor's Documents 1.11 Contractor's Use of Employer's Documents 1.12 Confidential Details 1.13 Compliance with Laws 1.14 Joint and Several Liability 2 THE EMPLOYER 2.1 Right of Access to the Site 2.2 Permits, Licences or Approvals 2.3 Employer's Personnel 2.4 Employer's Financial Arrangements 2.5 Employer's Claims THE ENGINEER 3.1 Engineer's Duties and Authority 3.2 Delegation by the Engineer 3.3 Instructions of the Engineer 3.4 Replacement of the Engineer 3.5 Determinations 4 THE CONTRACTOR 4.1 Contractor's General Obligations 4.2 Performance Security 4.3 Contractor's Representative 4.4 Subcontractors 4.5 Assignment of Benefit of Subcontract 4.6 Co-operation 4.7 Setting Out 4.8 Safety Procedures 4.9 Quality Assurance 4.10 Site Data 4.11 Sufficiency of the Accepted Contract Amount 4.12 Unforeseeable Physical Conditions 4.13 Rights of Way and Facilities 4.14 Avoidance of Interference 4.15 Access Route 4.16 Transport of Goods 4.17 Contractor's Equipment 4.18 Protection of the Environment 4.19 Electricity, Water and Gas 4.20 Employer's Equipment and Free-Issue Material 4.21 Progress Reports 4.22 Security of the Site 4.23 Contractor's Operations on Site 4.24Fossils 5 NOMINATED SUBCONTRACTORS 5.1 Definition of "nominated Subcontractor" 5.2 Objection to Nomination 5.3 Payments to nominated Subcontractors 5.4 Evidence of Payments 6 STAFF AND LABOUR 6.1 Engagement of Staff and Labour 6.2 Rates of Wages and Conditions of Labour 6.3 Persons in the Service of Others 6.4 Labour Laws 6.5 Working Hours 6.6 Facilities for Staff and Labour 6.7 Health and Safety 6.8 Contractor's Superintendence 6.9 Contractor's Personnel 6.10 Records of Contractor's Personnel and Equipment 6.11 Disorderly Conduct 7 PLANT, MATERIALS AND WORKMANSHIP 7.1 Manner of Execution 7.2 Samples 7.3 Inspection 7.4 Firsting 7.5 Rejection 7.6 Remedial Work 7.7 Ownership of Plant and Materials 7.8 Royalties 8 COMMENCEMENT, DELAYS AND SUSPENSION 8.1 Commencement of Works 8.2 Time for Completion 8.3 Programme 8.4 Extension of Time for Completion 8.5 Delays Caused by Authorities 8.6 Rate of Progress 8.7 Delay Damages 8.8 Suspension of Work 8.9 Consequences of Suspension 8.10 Payment for Plant and Materials in Event of Suspension 8.11 Prolonged Suspension 8.12 Resumption of Work 9 TESTS ON COMPLETION 9.1 Contractor's Obligations 9.2 Delayed Tests 9.3 Retesting 9.4 Failure to Pass Firsts on Completion 10 EMPLOYER'S TAKING OVER 10.1 Taking Over of the Works and Sections 10.2 Taking Over of Parts of the Works 10.3 Interference with Firsts on Completion 10.4 Surfaces Requiring Reinstatement 11 DEFECTS LIABILITY 11.1 Completion of Outstanding Work and Remedying Defects 11.2 Cost of Remedying Defects 11.3 Extension of Defects Notification Period 11.4 Failure to Remedy Defects 11.5 Removal of Defective Work 11.6 Further Firsts 11.7 Right of Access 11.8 Contractor to Search 11.9 Performance Certificate 11.10 Unfulfilled Obligations 11.11 Clearance of Site 12 MEASUREMENT AND EVALUATION 12.1 Works to be Measured 12.2 Method of Measurement 12.3 Evaluation 12.4 Omissions 13 VARIATIONS AND ADJUSTMENTS 13.1 Right to Vary 13.2 Value Engineering 13.3 Variation Procedure 13.4 Payment in Applicable Currencies 13.5 Provisional Sums 13.6 Daywork 13.7 Adjustments for Changes in Legislation 13.8 Adjustments for Changes in Cost 14 CONTRACT PRICE AND PAYMENT 14.1 The Contract Price 14.2 Advance Payment 14.3 Application for Interim Payment Certificates 14.4 Schedule of Payments 14.5 Plant and Materials intended for the Works 14.6 Issue of Interim Payment Certificates 14.7 Payment 14.8 Delayed Payment 14.9 Payment of Retention Money 14.10 Statement at Completion 14.11 Application for Final Payment Certificate 14.12 Discharge 14.13 Issue of Final Payment Certificate 14.14 Cessation of Employer's Liability 14.15 Currencies of Payment 15 DEFAULT OF CONTRACTOR 15.1 Notice to Correct 15.2 Termination by Employer 15.3 Valuation at Date of Termination 15.4 Payment after Termination 15.5 Employer's Entitlement to Termination for Convenience 16 DEFAULT OF EMPLOYER 16.1 Contractor's Entitlement to Suspend Work 16.2 Termination by Contractor 16.3 Cessation of Work and Removal of Contractor's Equipment 16.4 Payment on Termination 17 RISK AND RESPONSIBILITY 17.1 Indemnities 17.2 Contractor's Care of the Works 17.3 Employer's Risks 17.4 Consequences of Employer's Risks 17.5 Intellectual and Industrial Property Rights 17.6 Limitation of Liability 18 INSURANCE 18.1 General Requirements for Insurances 18.2 Insurance for Works and Contractor's Equipment 18.3 Insurance against Injury to Persons and Damage to Property 18.4 Insurance for Workers 19 FORCE MAJEURE 19.1 Definition of Force Majeure 19.2 Notice of Force Majeure 19.3 Time of Notice 19.4 Duty to Minimise Delay 19.5 Consequences of Force Majeure 19.6 Optional Termination, Payment and Release 19.7 Release from Performance under the Law 20 CLAIMS, DISPUTES AND ARBITRATION 20.1 Contractor's Claims 20.2 Appointment of the Dispute Adjudication Board 20.3 Failure to Agree Dispute Adjudication Board 20.4 Obtaining Dispute Adjudication Board's Decision 20.5 Amicable Settlement 20.6 Arbitration 20.7 Failure to Comply with Dispute Adjudication Board's Decision 20.8 Expiry of Dispute Adjudication Board's Appointment APPENDIX A GENERAL CONDITIONS OF DISPUTE ADJUDICATION AGREEMENT ANNEX: PROCEDURAL RULES INDEX OF SUB-CLAUSES B. PARTICULAR CONDITIONS PART A - CONTRACT DATA PART B - SPECIFIC PROVISIONS C. SAMPLE FORMS FORMS OF SECURITIES

International Federation of Consulting Engineers
FIDIC Bookshop - Box 311 - CH-1215 Geneva 15 - Switzerland
Tl +41-22-799 49 00 - Fx +41-22-799 490 1 - [email protected] - FIDIC Bookshop